Citation
2018/MH/Centrik/46/MAHARERA

Party to the case
Ankush Dewan V/s Bhoomi & Arkade Associates

Brief Facts
"The Complainant has purchased an apartment bearing No. 81303 in the Respondent's project 'Acropolis-2' located at Virar, Thane via a registered agreement for sale dated December 23, 2015 as per which the possession date was of March 31, 2016 and respondent failed to deliver the possession. the Respondents explained that the delay in handing over possession of the said apartment has been due to mitigating circumstances, beyond the control of the Respondents and for whicl! extension of time is well stipulated for in the said agreement for sale. However, they added, that they are now in a position to hand over the apartment to the Complainant in next 6 to 8 months."

Held
"The Authority directed the respondents directed to handover the possession of the said apartment to the complainant before the period ending May 2018, with OC, failing which the respondent shall be liable to pay interest to the complainant from June 01, 2018 till the actual date of possession, on the entire amount paid by the complainants to the respondent. The said interest shall be as prescribed under Rule 18 of the Maharashka Real Estate (Regulation and Development) (Registration of Real Estate Projects, Regishation of Real Estate Agents, Rate of Interest and Disclosures on Website) Rules, 2017."

Authority
MUMBAI

Get your first FREE consultation today

GET STARTED

Latest Blogs

Our Latest Blogs

UP-RERA takes over Unnati Fortune’s deregistered Aryana Project
Posted on 0 CommentsCategories RERA ConsultingTags , ,
Test One of the first projects to be deregistered by UP-RERA and the subsequent proceedings will decide how well RERA will...
Impact of RERA so FAR
Posted on 0 CommentsCategories RERA ConsultingTags , , , , ,
Test RERA, has taken cognizance of the multiple ways by which consumers have been cheated in the past, and provided for...
Critical Analysis of RERA
Posted on 0 CommentsCategories RERA ConsultingTags , , , , ,
Test The act was introduced to curb the mal-practices and the abuses caused to the customer. The act intends to protect...
A new tool in the hands of RERA Authorities
Posted on 0 CommentsCategories RERA ConsultingTags , , , ,
Test The RERA Act empowers the Regulatory authority to call for information or conduct investigations. These investigations have been mainly in...
Brief Introduction to RERA
Posted on 0 CommentsCategories RERA ConsultingTags , , , , ,
Test Over the course of the last two years, RERA has come up and grown as an effective weapon for consumers...
MahaRERA Opens-up door for Revocation
Posted on 0 CommentsCategories RERA ConsultingTags ,
Test MahaRERA has wide order No 8/19 dated 28th March 2019 opened up door for revocation of the registration in accordance...
UPRERA adopts satellite mapping to monitor Illegal construction
Posted on 0 CommentsCategories RERA ConsultingTags ,
Test After MahaRERA, UPRERA also has adopted the services of a satellite to monitor the illegal construction and dubious projects being...
UPRERA gets tough: Rejects Applications of 36 Builders
Posted on 0 CommentsCategories RERA ConsultingTags ,
Test The Uttar Pradesh Real Estate Regulatory Authority, Greater Noida Bench had rejected the registration applications of as many as 36...
NCR is the King, when it comes to delayed realty projects
Posted on 0 CommentsCategories RERA ConsultingTags ,
Test RERA Act has already been functional in all cities of NCR for almost 2 years now and still, such big...
Should RERA Authorities grant refund to the every complainant?
Posted on 0 CommentsCategories RERA ConsultingTags , , ,
Test The officials of the UPRERA Authority have decided not to encourage refund if the project is not stalled and have...
RERA: Builder has the duty to make association
Posted on 0 CommentsCategories RERA ConsultingTags , ,
Test The Builder is not mandatory but it is the sole responsibility of the builder to enable the formation of the...
MahaRERA issues notices for the recovery of money
Posted on 0 CommentsCategories RERA ConsultingTags , , , ,
Test Under Section 40 (1) of the RERA Act 2016, the authority can issue recovery warrants against developer who failed to...
Developers refraining from registering with RERA
Posted on 0 CommentsCategories RERA ConsultingTags , , ,
Test It's been around 2 years of implementation of the RERA Act, various developers have failed to get their projects to...
MahaRERA rules on applicability of section-12 and 18 of RERA
Posted on 0 CommentsCategories RERA ConsultingTags , , ,
Test While dismissing the complaint the authority observed that both the Section i.e. 12 and 18 operate at two separate times...
Bihar RERA freezes bank accounts of builder
Posted on 0 CommentsCategories RERA ConsultingTags , ,
Test Bihar RERA Authority exercising power under Section-36 of the Act which gives power to the Authority to pass interim orders...
HC issues notice to center over discrepancy in RERA
Posted on 0 CommentsCategories RERA ConsultingTags , , , , ,
Test The Hon’ble bench Division Bench of Justice Mahesh Grover and Justice Lalit Batra after hearing the arguments on behalf of...
Noida: UPRERA survey expects delivery of 40,000 flats
Posted on 0 CommentsCategories RERA ConsultingTags ,
Test The all the steps taken by the UPRERA Authority is now finally giving some lucrative results and the long wait...
New Year to bring changes in RERA
Posted on 0 CommentsCategories RERA ConsultingTags , , , ,
Test Central government is looking forward to bring a (removal of dificulties) order under section 91 of Real Estate and Regulation...